Newspaper Archive of
Post-Gazette
Boston, Massachusetts
Lyft
February 24, 2012     Post-Gazette
PAGE 14     (14 of 16 available)        PREVIOUS     NEXT      Full Size Image
 
PAGE 14     (14 of 16 available)        PREVIOUS     NEXT      Full Size Image
February 24, 2012
 

Newspaper Archive of Post-Gazette produced by SmallTownPapers, Inc.
Website © 2017. All content copyrighted. Copyright Information.     Terms Of Use.     Request Content Removal.




Page14 POST-GAZETTE, FEBRUARY 24, 2012 LEGAL NOTICE MASSACHUSETFS PORT AUTHORITY NOTICE TO CONTRACTORS Sealed General Bids for MPA Contract No. L1065-Cl, MITIGATION SOUNDPROOFING PROJ- ECT, CHELSEA, EAST BOSTON, REVERE, AND WINTHROP, MASSACHUSETTS, will be re- ceived by the Massachusetts Port Authority at the Capital Programs Department Office, Suite 209S - Logan Office Center, One Harborside Drive, East Boston, Massachusetts 02128-2909, until 11:00 A.M. local time on WEDNESDAY, MARCH 21, 2012, immediately after which, in a designated room, the proposals will be opened and read publicly. Sealed filed sub-bids for the same contract will be received at the same office until 11:00 A.M. local time on WEDNESDAY, MARCH 14, 2012, immediately after which, in a designated room, the filed sub-bids will be opened and read publicly. NOTE: PRE-BID CONFERENCE WILL BE HELD AT THE MASSPORT PRODUCT DISPLAY CENTER, 42 LEE BURBANK HIGHWAY (RTE. 1A SOUTH), AT 9:00 A.M. LOCAL TIME ON THURSDAY, MARCH 1, 2012. The work includes ALL LABOR, MATERIALS, AND EQUIPMENT NECESSARY FOR MAKING IM- PROVEMENTS TO THE ACOUSTICAL PERFORMANCE OF FORTY (40) SINGLE AND MULTI- FAMILY RESIDENTIAL STRUCTURES COMPRISING APPROXIMATELYSEVENTY TWO (72) DWELLING UNITS AND THREE (3) CONDOMINIUM BUILDINGS WITH EIGHT (8) UNITS; INSTALLATION OF ACOUSTICAL REPLACEMENT WINDOWS, STORM WINDOWS, PRIMARY DOORS, STORM DOORS, PAINTING AND INCIDENTAL WORK. Bid documents will be made available beginning TUESDAY, FEBRUARY 28, 2012. In order to be eligible and responsible to bid on this contract General Bidders must submit with their bid a current Certificate of Eligibility issued by the Division of Capital Asset Management and an Update Statement. The General Bidder must be certified in the category of DOORS AND WINDOWS OR GENERAL CONSTRUCTION. The estimated contract cost is $1,750,000.00. In order to be eligible and responsible to bid on this contract, filed Sub-bidders must submit with their bid acurrent Sub-bidder Certificate of Eligibility issued by the Division of Capital Asset Management and an Update Statement. The filed Sub-bidder must be certified in the sub-bid category of work for which the Sub-bidder is submitting a bid proposal. Bid Documents in electronic format may be obtained free of charge at the Authority's Capital Pro- grams Department Office, together with any addenda or amendments, which the Authority may issue and a printed copy of the Proposal form. Bidding procedures and awara of the contract and sub-contracts shall be in accordance with the provisions of Sections 44A through 44H inclusive. Chaoter 149 of the General Laws of the Com- monwealth of Massachusetts A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) percent of the value of the bid: when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bond, or cash, or a certified check, or a treasurer's or a cashier's check issued by a responsible bank or trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid. The successful Bidder will be required to furnish a performance bond and a labor and materials payment bond. each in an amount equal to 100% of the Contract price. The surety shall be a surety company or securities satisfactory to the Authority. Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149, Massachusetts General Laws, Section 26 to 27G. inclusive, as amended. The Contractor will be required to pay minimum wages in accordance with the schedules listed in Division I1. Special Provisions of the SpeCifications, which wage rates have been predeterminedby the U. S. Secretary of Labor and/or the Commis- sioner of Labor and Industries of Massachusetts, whichever is greater. The successful Bidder wilt be required to purchase and maintain Bodily Injury Liability Insurance and Property Damage Liability Insurance for a combined single limit of $1,000,000.00. Said policy shall be on an occurrence basis and the Authority shall beincluded as an Additional Insured See the insurance sections of Division I, General Requirements and Division II, Special Provisions for complete details. Filed sub-bids will be required and taken on the following classes of work: PAINTING The Authority reserves the dght to reject any sub-bid of any sub-trade where permitted by Section 44E of the above-referenced General Laws. The dght is also reserved to waive any informality in or to reject any or all proposals and General Bids. This contract is subject to a Disadvantaged Business- Enterprise participation provision requiring that not less than 5% of the Contract be performed by disadvantaged business enterprise contractors. With respect to this provision, bidders are urged to familiarize themselves thoroughly with the Bid: ding Documents. Strict compliance with the pertinent procedures will be required for a bidder to be deemed responsive and eligible. This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority contained in the Non-Discrimination and Affirmative Action article of Division I. General Require- ments and Covenants. and to the Secretary of Labor's Requirement for Affirmative Action to Ensure Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications (Executive Order 11246). The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to award of the Contract, and to notify prospective subcontractors of the requirement for such certifica- tion where the subcontract exceeds $10,000. A Contractor having fifty (50) or more employees and his subcontractors having fifty (50) or more employees who may be awarded a subcontract of $50.000 or more will. within one hundred twenty (120) days from the contract commencement, be required to develop a written affirmative action compliance program for each of its establishments. Compliance Reports - Within thirty (30) days of the award of this Contract the Contractor shall file a compliance report (Standard Form [SF 100])if: (a) The Contractor has not submitted a complete compliance report within twelve (12) months preceding the date of award, and (b) The Contractor is within the definition of "employer" in Paragraph 2c(3) of the instructions included in SF100. The contractor shall require the subcontractor on any first tier subcontracts, irrespective of the dollar amount, to file SF 100 within thirty (30) days after the award of the subcontracts, if the above two conditions apply. SF 100 will be furnished upon request. SF 100 is normally furnished Contractors annually, based on a mailing list currently maintained by the Joint Reporting Committee. In the event a contractor has not received the form, he may obtain it by writing to the following address: Joint Reporting Committee 1800 G Street Washington, DC 20506 Complete information and authorization to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Port Authority. The right is reserved to waive any informality in or reject any or all proposals. MASSACHUSETTS PORT AUTHORITY DAVID S. MACKEY INTERIM CHIEF EXECUTIVE OFFICER AND EXECUTIVE DIRECTOR Run date: 02/24/12 POST-GAZETTE EAST BOSTON SATELLITE OFFICE is NOW OPEN 35 Bennington Street, East Boston 617.227.8929 TUES. 10:00 A.M. - 3:00 P.M. THURS. 11:00 A.M.- 2:00 P.M. ACCEPTING Advertisements VISIT THE POST-GAZETTE ON LINE AT WWW.BOSTON POSTGAZETTE.COM I General Advertisements Sales and Rentals Memorials Legals ADVERTISING WILL MAKE A DIFFERENCE LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Middlesex Probate and Family Court 208 Cambridge Street Cambridge, MA 02141 Docket No. MI12P0705EA In the Estate of RENA E. GESMER Late of NEWTON, MA 02460-0007 Date of Death January 26, 2012 NOTICE OF PETITION FOR PROBATE OF WILL To all persons interested in the above captioned estate, a petition has been presented requesting that a document purporting to be the last will and codicil of said decedent be proved and allowed and that LeeT. Gesmer of Dover, MA and Susan L. Gesmer of Goshen, MA be appointed executor/tdx, named in the wilt to serve Without Surety. IF YOU DESIRE TO OBJECT THERETO, YOU OR YOUR ATTORNEY MUST FILE A WRITTEN APPEARANCE IN SAID COURT AT CAMBRIDGE ON OR BEFORE TEN O'CLOCK IN THE MORNING (10:00 AM) ON MARCH 15, 2012. In addition, you must file a wdtten affidavit of objections to the petition, stating specific facts and grounds upon which the objection is based, within [30) days after the return day (or such other time as the court, on motion with notice to the petitioner, may allow) in accor- dance with Probate Rule 16. MUPC SUPPLEMENTAL NOTICE To all persons who may have an interest in the above-captioned estate, the Division of Medical Assistance and, if interested, to the Office of the Attorney General and the United States Department of Veterans Affairs; Notice is being sent to you as you may have a legal interest in this case. in order to inform you of your rights. Under the new Massachusetts Uniform Probate Code Inventory and Accounts are not required to be filed with the Court, but interested parties are entitled to notice regarding the administration from the Personal Representative and can Petition the Court in any matter relating to the estate, including distribution of assets and expenses of administration. Interested par- ties are entitled to Petition the Court to insti- tute formal proceedings and to obtain orders terminating or restricting the powers of the appointed Personal Representative. Petitioner requests to be permitted to file a MUPC Bond. WITNESS HON. PETER C. DiGANGI, First Justice of this Court. Date: February 16, 2012 Tara E. DeCristofaro, Register of Probate Run date: 2/24/12 LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Middlesex Probate and Family Court 208 Cambridge Street Cambridge, MA 02141 Docket No. MI12P0737EA In the Estate of WANDA C. TARVER Late of WAYLAND, MA 01778 Date of Death December 29, 2011 NOTICE OF PETITION FOR PROBATE OF WILL To all persons interested in the above captioned estate, a petition has been presented requesting that a document purporting to be the last will of said decedent be proved and allowed and that Steven E. Tarver of Leominster. MA and Susan B.Tarver of Saco. ME be appointed executor/trix, named in the will to serve Without Surety. IF YOU DESIRE TO OBJECT THERETO. YOU OR YOUR ATTORNEY MUST FILE A WRITTEN APPEARANCE IN SAID COURT AT CAMBRIDGE ON OR BEFORE TEN O'CLOCK IN THE MORNING (10:00 AM) ON MARCH 16, 2012. In addition, you must file a written affidavit of objections to the petition, stating specific facts and grounds upon which the objection is based, within (30) days after the return day (or such other time as the court, on motion with notice to the Iefitioner, may allow) in accor- dance with Probate Rule 16. MUPC SUPPLEMENTAL NOTICE To atl persons who may have an interest in the above-captioned estate, the Division of Medical Assistance and. if interested, to the Office of the Attomey General and the United States Department of Veterans Affairs; Notice is being sent to you as you may have a legal interest in this case, in order to inform you of your rights. Under the new Massachusetts Uniform Probate Code Inventory and Accounts are not required to be filed with the Court, but interested parties are entitled to notice regarding the administration from the Personal Representative and can Petition the Court in any matter relating to the estate, including distribution of assets and expenses of administration. Interested par- ties are entitled to Petition the Court to insti- tute formal proceedings and to obtain orders terminating or restricting the powers of the appointed Personal Representative. Petitioner requests to be permitted to file a MUPC Bond. WITNESS, HON. PETER C. DiGANG[, First Justice of this Court. Date: February 17, 2012 Tara E. DeCristofaro, Register of Probate Run date: 2/24/12 k._ Real Estate Matt6o Gallo Appraisals Sales & Rentals 376 North Street * Boston, MA 02113 (617)523-2100 Fax (617) 523-3530 LEGAL NOTICE MASSACHUSETTS PORT AUTHORITY NOTICE TO CONTRACTORS Sealed General Bids for MPA Contract NO. A203-C1 AUTHORITY-WIDE WATER METER UP- GRADE AND REPLACEMENT PROJECT, LOGAN INTERNATIONAL AIRPORT, BOSTON, MASSACHUSETTS, will be received by the Massachusetts Port Authority at the Capital Programs Department ffice, Suite 209S, Logan Office Center. One Harborside Drive. East Boston, Massa- chusetts 02128-2909, until 11:00 A.M. local time on WEDNESEDAY, MARCH 21, 2012 immediately after which, in a designated room, the bids will be opened and read publicly. NOTE: PRE-BID CONFERENCE WILL BE HELD AT THE CAPITAL PROGRAMS DEPARTMENT (ABOVE ADDRESS) AT 1!00 PM LOCAL TIME ON FRIDAY. MARCH 2 2012. The work includes AUTHORITY-WIDE PLUMBING WORK TO INCLUDE REPLACEMENTS AND UPGRADES TO DOMESTIC WATER SERVICES AND METERS. Bid documents will be made available beginning TUESDAY, FEBRUARY 28, 2012. In order to be eligible and responsible to bid on this contract General Bidders must submit with their bid a current Certificate of Eligibility issued by the Division of Capital Asset Management and an Up- date Statement. The General Bidder must be certified in the category of PLUMBING. The estimated contract cost is $1,600,000.00. Bid Documents in electronic format may be obtained free of charge at the Authodty's Capital Pro- grams Department Office, together with any addenda or amendments, which the Authority may issue and a printed copy of the Proposal form. Bidding procedures and award of the contract and sub-contracts shall be in accordance with the )rovisions of Sections 44A through 44J inclusive. Chapter 149 of the General Laws of the Com- monwealth of Massachusetts. A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) )ercent of the value of the bid: when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bond. or cash. or a certified check or a treasurer's or a cashier's check issued by a responsible bank or trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid. The successful Bidder will be required to furnish a performance bond and a labor and materials payment bond. each in an amount equal to 100% of the Contract price. The surety shall be a surety company or securities satisfactory to the Authority. Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149. Massachusetts General Laws. Section 26 to 27G, inclusive, as amended. The Contractor will be required to pay minimum wages =n accordance with the schedules listed in Division II, Special Provisions of the Specifications, which wage rates have been predetermined by the U. S. Secretary of Labor and/or the Commis- sioner of Labor and Industries of Massachusetts. whichever is greater. The successful Bidder will be required to purchase and maintain Bodily Injury Liability Insurance and Properly Damage Liability Insurance for a combined single limit of $10,000,000.00. Said policy shall be on an occurrence basis and the Authority shall be included as an Additional Insured. See the insurance sections of Division I, General Requirements and Division II, Special Provisions for complete details. No filed sub-bids will be required for this contract. This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority contained in the Non-Discrimination and Affirmative Action article of Division I. General Require- ments and Covenants. and to the Secretary of Labor's Requirement for Affirmative Action to Ensure Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications Executive Order 11246). The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to award of the Contract, and to notify prospective subcontractors of the requirement for such certifica- tion where the subcontract exceeds $10,000. Complete information and authodzation to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Port Authority. The right is reserved to waive any informality in or reject any or all proposals. MASSACHUSETTS PORT AUTHORITY DAVID S, MACKEY INTERIM CHIEF EXECUTIVE OFFICER AND EXECUTIVE DIRECTOR Run date: 02/24/12