Newspaper Archive of
Post-Gazette
Boston, Massachusetts
Lyft
March 2, 2012     Post-Gazette
PAGE 14     (14 of 16 available)        PREVIOUS     NEXT      Full Size Image
 
PAGE 14     (14 of 16 available)        PREVIOUS     NEXT      Full Size Image
March 2, 2012
 

Newspaper Archive of Post-Gazette produced by SmallTownPapers, Inc.
Website © 2017. All content copyrighted. Copyright Information.     Terms Of Use.     Request Content Removal.




Page 14 POST-GAZE'n'E, MARCH 2, 2012 LEGAL NOTICE I MASSACHUSETTS PORT AUTHORITY [ NOTICE TO CONTRACTORS I Sealed General Bids for MPA PROJECT NO. LP1207-Cl, FY2013-FY2015, SKILLED TRADES I MAINTENANCE CONTRACT FOR CARGO BUILDINGS NOS. 56, 57, 56, 62, 63, GREEN BUS I DEPOT AND OFFICE BUILDING NO. 11, LOGAN INTERNATIONAL AIRPORT, EAST BOSTON I MASSACHUSE'n's 02128, will be received by the Massachusetts Port Authority at the Capital Pro- grams Department Office, Suite 209S, Logan Office Center, One Harberside Drive, East Boston, [ Massachusetts 02128-2909, until 11:00 A.M. local time on WEDNESDAY, APRIL 4, 2012, immedi- I ately after which, in a designated room, the proposal will be opened and read publicly. I NOTE: PRE-BiD CONFERENCE WILL BE HELD AT THE CAPITAL PROGRAMS DEPART- I MENT, LOGAN OFFICE CENTER, SUITE 209S, ONE HARBORSlDE DRIVE, I EAST BOSTON, MASSACHUSETTS AT 10:00 A.M. LOCAL TIME ON I FRIDAY, MARCH 9, 2012. I THE WORK INCLUDES THE MAINTENANCE, CONTRACT COORDINATION AND ADMINISTRA- I "lION OF THE BUILDINGS, PROPERTY AND EQUIPMENT IDENTIFIED IN DIVISION III AND I LOCATED AT SOUTH CARGO BUILDINGS NOS. 56, 57, 56, 62,63, GREEN BUS DEPOT AND I OFFICE BUILDING NO. 11, LOGAN INTERNATIONAL AIRPORT, EAST BOSTON, MA 02128. I Bid documents will be made available beginning MONDAY, MARCH 5, 2012. The estimated project cost is ONE MILLION DOLLARS ($1,000,000.00) / Bid Documents may be obtained free of charge at the Authority's Capital Programs Department Of- f rice, together with any addenda or amendments, which the Authority may issue and a printed copy | of the Proposal form. Bidding procedures and award of the contract and sub-contracts shall be in accordance with the provisions of Sections 44A through 44J inclusive, Chapter 149 of the General Law s of the Common- | wealth of Massachusetts. A proposal guaranty shall be submitted with each General Bid consisting | of a bid deposit for five (5) percent of the value o1 the bid; when sub-bids are required, each must be | accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bond, | or cash, or a certified check, or a treasurer's or a cashier's check issued by a responsible bank or | trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the l work is to be executed. The bid deposit shall be (a) in a formsatisfactory to the Authority, (b) with a | surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and l (o) conclitioned upon the faithful performance by the principal of the agreements contained in the bid. | The successful Bidder will be required to furnish a one-year renewable performance bond and a | one-year renewable labor and materials payment bond, each in an amount equal to one hundred | percent (100%) of the Contract Price. The surety shall be a surety company or securities satisfactory | to the Authority. / The successful Bidder will be required to purchase and maintain Bodily Injury Liability Insurance / and Property Damage Liability Insurance for a combined single limit of ONE MILLION DOLLARS | ($1,000,000.00). Said policy shall be on an occurrence basis and the Authority shall be included as l an Additional Insured. See the insurance sections of Division I, General Requirements and Division / II, Special Provisions for complete details. / No filed sub-bids will be required for this project. ] This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority | contained in the Non-Discrimination and Affirmative Action article of Division I, General Require- l ments and Covenants, and to the Secretary of Labor's Requirement for Affirmative Action to Ensure | Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications | (Executive Order 11246). | The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to l award of the Contract, and to notify prospective subcontractors of the requirement for such certifica- | tion where the subcontract exceeds $10,000. / Complete information and authorization to view the site may be obtained from the Capital Programs | Department Office at the Massachusetts Port Authority. The right is reserved to waive any informality | in or reject any or all proposals. | MASSACHUSETTS PORT AUTHORITY | DAVID S. MACKEY | INTERIM CHIEF EXECUTIVE OFFICER & EXECUTIVE DIRECTOR | Run date: 03/02/12 / LEGAL NOTICE MASSACHUSE'Fi'S PORT AUTHORITY NOTICE TO CONTRACTORS Sealed General Bids for MPA Contract No. AP1220-C1, FY 2013 - 2014 ROOF MAINTENANCE TERM CONTRACT, AT ALL MASSPORT FACILITIES, BOSTON AND BEDFORD, MASSACHUSETrS, , will be received by the Massachusetts Port Authority at the Capital Programs Department Office, Suite 209S, Logan Office Center, One Harbors|de Drive, East Boston, Massachusetts 02128-2909, until 11:00 AM. local time on WEDNESDAY, April 4, 2012 immediately after which, in a designated room, the bids will be opened and read publicly. NOTE: PRE-BID CONFERENCE WILL BE HELD AT THE CAPITAL PROGRAMS DEPART- MENT, SUITE 209S, LOGAN OFFICE CENTER, ONE HARBORSlDE DRIVE, EAST BOSTON, MASSACHUSETTS, AT 10:00 A.M. LOCAL TIME ON MONDAY, MARCH 12, 2012. The work includes: PROVISION OF LABOR, INCIDENTAL MATERIALS, TOOLS, EQUIPMENT AND SERVICES TO REPAIR AND MAINTAIN ALL ROOFING SYSTEMS AT ALL PROPERTIES UNDER THE CONTROL OF THE AUTHORITY, AS REQUIRED FROM TIME TO TIME, ON AN AS NEEDED/ON CALL BASIS, FOR A TIME PERIOD OF TWENTY-FOUR (24) MONTHS. Bid documents will be made available beginning MONDAY, MARCH 5, 2012. In order to be eligible and responsible to bid on this contract General Bidders must submit with their bid a current Certificate of Eligibility issued by the Division of Capital Asset Management and an Update Statement. The General Bidder must be certified in the category of ROOFING. The estimated contract cost is FOUR HUNDRED AND FIFTY THOUSAND DOLLARS ($450,000.00). Bid Documents in electronic format may be obtained free of charge at the Authority's Capital Pro- grams Department Office, together with any addenda or amendments, which the Authority may issue and a printed copy of the Proposal form. Bidding procedures and award of the contract and sub-contracts shall be in accordance with the provi- sions of Sections 44A through 44J inclusive, Chapter 149 of the General Laws of the Commonwealth of Massachusetts. A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) percent of the value of the bid; when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bond, or cash, or a certified check, or a treasurer's or a cashier's check issued by a responsible bank or trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid. The successful Bidder will be required to furnish a performance bend and a labor and materials payment bond, each in an amount equal to 100% of the Contract price. The surety shall be a surety, company or securities satisfactory to the Authority, Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149, Massachusetts Genera[ Laws, Section 26 to 27G, inclusive, as amended. The Contractor will be required to pay minimum wages in accordance with the schedules listed in Division II, Special Provisions of the Specifications, which wage rates have been predetermined by the U. S. Secretary of Labor and/or the Commissioner of Labor and Industries of Massachusetts, whichever is greater. The successful Bidder wig be required to purchase and maintain Bodily Injury Liability Insurance and Property Damage Liability Insurance for a combined single limit of TEN MILLION DOLLARS ($10,000,000.00). Said policy shall be on an occurrence basis and the Authority shall be included as an Additional Insured. See the insurance sections of Division I, General Requirements and Division II, Special Provisions for complete details. No filed sub-bids will be required for this contract. This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority contained in the Non-Discrimination and Affirmative Action article of Division I, General Require- ments and Covenants, and to the Secretary of Labor's Requirement for Affirmative Action to Ensure Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications (Executive Order 11246). The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to award of the Contract, and to notify prospective subcontractors of the requirement for such certifica- tion where the subcontract exceeds $10,000. Complete information and authorization to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Pert Authority. The right is reserved to waive any informality in or reject any or all proposals. MASSACHUSETI'S PORT AUTHORITY DAVID S. MACKEY INTERIM CHIEF EXECUTIVE OFFICER AND EXECUTIVE DIRECTOR Run date: 03/02/12 Groundwater (Continued MBTA, Department of Con- servation and Recreation, and MassDOT have made significant investments in repairs that have removed multiple potential sources of groundwater drawdown. The City established a Ground- water Conservation Overlay District (GCOD) that compels those undertaking construc- tion to make sure not to re- duce groundwater levels and to recharge rainwater into the ground. As a result of these and other efforts, we have begun to see increases in groundwater levels in LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Middlesex Probate and Family Court 208 Cambridge Street Cambridge, MA 02141 Docket No. MI12P0888EA In the Estate of HAROLD A. NORDSTROM Late of North Reading, MA 01864 Date of Death July 17, 1996 NOTICE OF PETITION FOR APPOINTMENT OF ADMINISTRATOR To all persons interested in the above captioned estate, a petition has been presented requesting that Mark F. Morganelli of Wilmington, MA or some other suitable person be appointed administrator of said estate to serve With Corporate Surety. IF YOU DESIRE TO OBJECT THERETO, YOU OR YOUR ATTORNEY MUST FILE A WRITTEN APPEARANCE IN SAID COURT AT CAMBRIDGE ON OR BEFORE TEN O'CLOCK IN THE MORNING (10:00 AM) ON MARCH 26, 2012. WITNESS, Hon. PETER C. DiGANGI, First Justice of this Court. Date: February 27, 2012 Tara E. DeCristofaro, Register of Probate Run date: 3/2/12 LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Middlesex Probate and Family Court 206 Cambridge Street Cambridge, MA 02141 Docket No. MI12P0873EA In the Estate of KENNETH R. CROWELL Late of Melrose, MA 02176 Date of Death November 16, 2011 NOTICE OF PETITION FOR PROBATE OF WILL To all persons interested in the above captioned estate, a petition has been presented requesting that a document purporting to be the last will of said decedent be proved and allowed and that Eastern Bank of Boston, MA be appointed executor/trix, named in the will to serve Without Surety. IF YOU DESIRE TO OBJECT THERETO, YOU OR YOUR ATTORNEY MUST FILE A WRITTEN APPEARANCE IN SAID COURT AT CAMBRIDGE ON OR BEFORE TEN O'CLOCK IN THE MORNING (10:00 AM) ON MARCH 23, 2012. In addition, you must file a written affidavit of objections to the petition, stating specific facts and grounds upon which the objection is based, within (30) days after the return day (or such other time as the court, on motion with notice to the petitioner, may allow) in accordance with Probate Rute 16. MUPC SUPPLEMENTAL NOTICE To all persons who may have an interest in the above-captioned estate, the Division of Medical Assistance and, if interested, to the Office of the Attorney General and the United States Department of Veterans Affairs; Notice is being sent to you as you may have a legal interest in this case, in order to inform you of your rights. Under the new Massachusetts Uniform Probate Code Inventory and Accounts are not required to be filed with the Court, but interested parties are entitled to notice regarding the administration from the Personal Representative and can Petition the Court in any matter relating to the estate, including distribution of assets end ex- penses of administration. Interested parties are entitled to Petition the Court to institute formal proceedings and to obtain orders ter- minating or restricting the powers of the appointed Personal Representative. Petitioner requests to be permitted to file a MUPC Bond. WITNESS, Hon. PETER C. DiGANGI, First Justice of this Court. Date: February 24, 2012 Tara E. DeCristofaro, Register of Probate Run date: 3/2/12 from Page 1) many areas where they have long been below levels that could lead to piling dam- age. For example, in the Back Bay, DCR and BWSC have cooperated on a system that takes water that drains from the Storrow Drive tunnel and recharges it into the ground beneath Back Street; because of this effort, groundwater levels in this stretch have increased by around two feet. "The BGwT is pleased to have participated in the de- velopment of this important brochure," said Elliott Laffer, Executive Director of the Boston Groundwater Trust, "We look forward to working with additional property own- ers to help with any issues related to low groundwater and the protection of wooden pilings." The City of Boston's The Importance of Groundwater Level brochure provides a history of the groundwater problem in Boston, how the City of Boston is working with its partners to address the issue, and tools and resources for property own- ers to address or prevent the decline of groundwater levels at their property. The brochure also high- lights the Boston Transpor- tation Department's Com- plete Streets program that is currently piloting a storm water management approach that allows runoff from streets and sidewalks to fil- ter directly into the ground rather than being chan- neled into pipes. LEGAL NOTICE MASSACHUSETTS PORT AUTHORITY REQUEST FOR TRADE CONTRACTOR QUALIFICATIONS The MASSACHUSETTS PORT AUTHORITY is soliciting Statements of Qualifications from TRADE CONTRACTORS interested in performing work for MPA PROJECT NO. L269-Cl-5, DESIGN PACKAGE #2 and #3 LOGAN CONSOLIDATED RENTAL CAR FACILITY, LOGAN INTERNATIONAL AIRPORT, EAST BOSTON, MASSACHUSETTS. The Authority is seeking Qualification Statements from Trade Contractors who have a demonstrated experience in the construction and implementation of similar work in terms of scale and complexity as required for this project at Logan Airport in East Boston. In accordance with Massachusetts construction manager at-risk requirements, MGL Chapter 149A, Section 44F, Qualification Statements are being requested at this time from the following trade contractors: Resilient Flooring, Painting, Acoustical Tile, Terrazzo, Tile. The Consolidated Rental Car Facility Southwest Service Area Redevelopment project (COnRAC) includes a four-level 1,200,000 square foot precast concrete parking garage, a 112,000 square feet Customer Service Center (CSC) building, Quick Turnaround Areas (QTAs) for rental car maintenance and storage, including fueling, washing and cleaning facilities. The project includes site building structures, architecture, interior finishes, vehicular and pedestrian circulatiorayfinding, signage/ graphics, stairs, HVAC, plumbing, fire protection, electrical, lighting, power, security, and other systems and facilities. The total estimated cost of the Project is approximately $187,000,000 and the construction duration is approximately thirty (30) months. The estimated value of work to be performed by trade contractors is as follows: Resilient Fleering - $70,000 Painting - $940,000 Acoustical "131e - $775,000 Terrazzo - $1,860,000 Tile - $570,000 The Authority is implementing this project in accordance with MGL Chapter 149A, Sections 1 thru 13. This selection of trade contractors conforms to MGL Chapter 149A, Section 8, subsections (b) to (k) inclusive. This Request for Qualifications (RFQ) will be utilized to prequalify trade contractors capable and experienced in the construction of parking structures. The Authority shall utilize a two-step process including the prequaiification of trade contractors based on an evaluation of the Statement of Qualifications received in response to this solicitation, followed by an Invitation to Bidders that will only be issued to the prequalified trade contractors. A Prequalification Committee consisting of : four representatives, one each from the Designer and the CM at Risk and two Massport staff. This Prequalification Committee will be conducting a qualifications-based evaluation of submittals received from interested trade contractors in order to identify prequalified trade contractors who will be invited to respond to a written Invitation to Bidders. Qualification Statements shall be evaluated in accordance with the following criteria; (1) Management , Experience; (2) Project References including a Public Project Record and (3) Capac' to Complete ] including a demonstration that the contractor has the financial stability and long-term viability to successfully implement the Project. A Supplemental Information Package that discusses these Evaluation Criteria and the Prequalification Process in more detail as well as any other requirements for the Qualification Statements will be available to interested parties beginning Monday, March 5, 2012, by contacting Cynthia Monahan at cmonahan@massDort.com. Seven (7) copies of a bound document each limited to 20 sheets (40 pages), exclusive of covers and dividers and resumes, which shall be limited to one page, shall be printed on both sides of the sheet (8 " x 11") and shall be addressed to Mr. Houesam H. Sleiman, P.E., CCM, Director of Capital Programs and Environmental Affairs, and received no later than 12 Noon, Thursday, March 22, 2012, at the Massachusetts Port Authority, Logan Office Center, One Harborside Drive, Suite 209S, Logan International Airport, East Boston, MA 02128-2909. Any submittal that exceeds the page limit set here or that is not received in the Capital Programs Department by the above deadline shall be rejected as non-responsive. Questions regarding this RFQ shall be directed to Ms. Catherine Wetherell, Deputy Director, Capital Programs and Environmental Affairs, at 617-568-3501 or via email at cwetherell@massDort.cem. MASSACHUSE'I'rs PORT AUTHORITY DAVID S. MACKEY INTERIM CHIEF EXECUTIVE OFFICER & EXECUTIVE DIRECTOR Run date: 03/02/12