Newspaper Archive of
Post-Gazette
Boston, Massachusetts
Lyft
September 25, 2015     Post-Gazette
PAGE 15     (15 of 16 available)        PREVIOUS     NEXT      Full Size Image
 
PAGE 15     (15 of 16 available)        PREVIOUS     NEXT      Full Size Image
September 25, 2015
 

Newspaper Archive of Post-Gazette produced by SmallTownPapers, Inc.
Website © 2017. All content copyrighted. Copyright Information.     Terms Of Use.     Request Content Removal.




BOSTON POST-GAZETTE, SEPTEMBER 25, 2015 Page 15 MASSACHUSETTS PORT AUTHORITY NOTICE TO CONTRACTORS Sealed General Bids for MPA Contract No. APt 516-C2, FY16-17 PUMP & MOTOR SERVICE AND MAINTENANCE, BOSTON, BEDFORD, & CHARLESTOWN, MASSACHUSETrS, will be received by the Massachusetts Port Authority at the Capital Programs Department Offce, Suite 209S, Logan Office Center, One Harborside Drive, East Boston, Massachusetts 02128-2909, until 11:00 A.M. local time on WEDNESDAY, OCTOBER 21, 2015, immediately after which, in a designated room, the bids wilt be opened and read publicly. NOTE: PRE BID CONFERENCE WILL BE HELD AT THE CAPITAL PROGRAMS DEPARTMENT (ABOVE ADDRESS) AT 10:00 A.M. LOCAL TIME ON TUESDAY, OCTOBER 6, 2015. The work includes PROVIDE ALL LABOR, TOOLS, TESTING, EQUIPMENT AND MATERIALS TO SERVICE, MAINTAIN AND REPAIR WASTIEWATER, STORMWATER, CONDENSATE AND OTHER PROCESS PUMPS, MOTORS AND CONTROLS OF VARIOUS EQUIPMENT MANUFACTURERS FOR ALL MASSACHUSETTS PORT AUTHORITY FACILITIES IN BEDFORD, CHARLESTOWN, AND BOSTON, MASSACHUSETTS. Bid documents will be made available beginning WEDNESDAY, SEPTEMBER 30, 2015. Bid Documents in electronic format may be obtained free of charge at the Authority's Capital Programs Department Office, together with any addenda or amendments, which the Authority may issue and a printed copy of the Proposal form. The estimated contract cost is TWO HUNDRED FIFTY THOUSAND DOLLARS ($250,000.00). A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) percent of the value of the bid; when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bend, or cash, or a certified check, or a treasurer's or a cashier's check issued by a responsible bank or trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid. The successful Bidder will be required to famish a performance bond and a labor and materials payment bend, each in an amount equal to 100% of the Contract price. The surety shall be a surety company or securities satisfactory to the Authority. Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149, Massachusetts General Laws, Section 26 to 27G, inclusive, as amended. The Contractor will be required to pay minimum wages in accordance with the schedules listed in Division II, Special Provisions of the Specifications, which wage rates have been predetermined by the U. S. Secretary of Labor and/or the Commissioner of Labor and Industries of Massachusetts, whichever is greater. The successful Bidder will be required to purchase and maintain Bodily Injury Liability Insurance and Property Damage Liability Insurance for a combined single limit of ONE MILLION DOLLARS ($1,000,000.00). Said policy shall be on an occurrence basis and the Authority shall be included as an Additional Insured. See the insurance sections of Division I, General Requirements and Division II, Special Provisions for complete details. This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority contained in the Non-Discrimination and Affirmative Action article of Division I, General Requirements and Covenants, and to the Secretary of Labor's Requirement for Affirmative Action to Ensure Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications (Executive Order 11246), The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to award of the Contract, and to notify prospective subcontractors of the requirement for such certification where the subcontract exceeds $10,000. Complete information and authorization to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Port Authority. The right is reserved to waive any informality in or reject any or all proposals. MASSACHUSETTS PORT AUTHORITY THOMAS P. GLYNN CEO AND EXECUTIVE DIRECTOR Run date 9/25/2015 MASSACHUSETTS PORT AUTHORITY NOTICE TO CONTRACTORS Sealed General Bids for MPA Contract No. AP1531-C1, FY 2016-2019 TERM CONTRACT FOR ABATEMENT AND REMEDIATION, ALL MASSAGHUSE'n's PORT AUTHORITY FACILITIES, BOSTON, BEDFORD, AND WORCESTER, MASSACHUSETTS, will be received by the Massachusetts Port Authority at the Capital Programs Department Office, Suite 209S, Logan Office Center, One Harborside Drive, East Boston, Massachusetts 02128-2909, until 11:00 A.M. local time on WEDNESDAY, OCTOBER 28, 2015, immediately after which, in a designated room, the bids will be opened and read publicly. NOTE: PRE-BID CONFERENCE WILL BE HELD AT THE CAPITAL PROGRAMS DEPARTMENT (ABOVE ADDRESS) AT 11:00 a.m. LOCAL TIME ON THURSDAY, OCTOBER 15, 2015. The work includes ABATEMENT/REMEDIATION OF ASBESTOS AND ASBESTOS CONTAMINATED MATERIALS, PCB BULK PRODUCT/EXCLUDED PRODUCT, MICROBIALLY- IMPACTED/WATER-DAMAGED MATERIALS, LEAD-BASED PAINT COATED/CONTAMINATED SURFACES AND GUANO-COVERED/CONTAMINATED SURFACES; REINSULATION, REPLACEMENT, REPAIR AND RERNISHING IN CONJUNCTION WITH THIS WORK. Bid documents will be made available beginning WEDNESDAY, SEPTEMBER 30, 2015. Bid Documents in electronic format may be obtained free of charge at the Authority's Capital Programs Department Office, together with any addenda or amendments, which the Authority may issue and a printed copy of the Proposal form. In order to be eligible and responsible to bid on this contract General Bidders must submit with their bid a current Certificate of Eligibility issued by the Division of Capital Asset Management & Maintenance and an Update Statement. The General Bidder must be certified in the category of ASBESTOS REMOVAL. The estimated contract cost is SEVEN HUNDRED FIFTY THOUSAND DOLLARS ($750,000.00). Bidding procedures and award of the contract and sub-contracts shall be in accordance with the provisions of Sections 44A through 44../inclusive, Chapter 149 of the General Laws of the Commonwealth of Massachusetts. A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) percent of the value of the bid; when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount, in the form of a bid bond, or cash, or a certified check, or a treasurer's or a cashier's check issued by a responsible bank or trust company, payable to the Massachusetts Port Authority in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid. The successful Bidder will be required to furnish a performance bond and a labor and materials payment bond, each in an amount equal to 100% of the Contract price. The surety shall be a surety company or securities satisfactory to the Authority. Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149, Massachusetts General Laws, Section 26 to 27G, inclusive, as amended. The Contractor will be required to pay minimum wages in accordance with the schedules listed in Division II, Special Provisions of the Specifications, which wage rates have been predetermined by the U. S. Secretary of Labor and/or the Commissioner of Labor and Industries of Massachusetts, whichever is greeter. The successful Bidder will be required to purchase and maintain Bodily Injury Liability Insurance and Property Damage Liability Insurance for a combined single limit of $10,000,000. Said policy shall be on an occurrence basis and the Authority shall be included as an Additional Insured. See the insurance sections of Division I, General Requirements and Division ti, Special Provisions for complete details. No filed sub-bids will be required for this contract. This Contract is also subject to Affirmative Action requirements of the Massachusetts Port Authority contained in the Non-Discrimination and Affirmative Action article of Division I, General Requirements and Covenants, and to the Secretary of Labor's Requirement for Affirmative Action to Ensure Equal Opportunity and the Standard Federal Equal Opportunity Construction Contract Specifications (Executive Order 11246). The General Contractor is required to submit a Certification of Non-Segragated Facilities prior to award of the Contract, and to notify prospective sub-oontractors of the requirement for such certification where the sub-contTact exceeds $10,000. Complete information and authorization to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Port Authority. The right is reserved to waive any informality in or reject any or all proposals. MASSACHUSE'n's PORT AUTHORITY THOMAS P. GLYNN CEO AND EXECUTIVE DIRECTOR Run date: 9/25/2015 Yankees Took Good Gamble on Oscar Outfielder Oscar Gamble played for 17 seasons with seven different teams, but he will forever be remem- bered for his playing days with the NY Yankees and for his massive head of hair, His 1976 TOPPS baseball card drove Steinbrenner lit- erally bananas. After he saw the baseball card, he wasn't given a Yankees uni- form until he cut his hair. Gamble was supposed to be doing an afro hair commer- cial and wanted to keep his hair intact until after spring training, but the boss said no. Former catcher and then coach Elston Howard was given the assignment of making sure Gamble got to LEGAL NOTICE NOTICE OFSALE Notice is hereby given by TODISCO TOWING, 262 NORFOLK AVENUE, ROXBURY, MA pursuant to the pro- visions of Mass G.L. c 255, Section 39A, that they will sell the following vehicles: Vehicles are being sold to satisfy their garage keeper's lien for towing, storage and notices of sale: 2008 HONDA CiViC VIN #2HGFG 12848H541334 The above vehicle will be sold at auction at TODISCO TOWING, 262 NORFOLK AVENUE, ROXBURY, MA SUNDAY, SEPTEMBER 27, 2015 at 7:00AM Run dates: 9/11, 9/18, 9/25 2015 LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Probate and Family Court Middlesex Division 208 Cambridge Street East Cambridge, MA 02141 (617) 768-5800 Docket No. MI15P4449EA Estate of ANITA SHARETA ALLEN Date of Death April 16, 2008 INFORMAL PROBATE PUBLICATION NOTICE To all persons interested in the above captioned estate, by Petition of Petitioner Kim Allen of Gretna, LA. Kim Allen of Gretna, LA has been informally appointed as the Personal Representative of the estate to serve without surety on the bend. The estate is being administered under informal procedure by the Personal Represen- tative under the Massachusetts Uniform Pro- bate Cede without supervision by the Court. Inventory and accounts are not required to be filed with the Court, but interested par'des are entitled to notice regarding the administration from the Personal Representative and can petition the Court in any matter relating to the estate, including distribution of assets and expenses of administration. Interested parties are entitled to petition the Court to institute formal proceedings and to obtain orders terminating or restricting the powers of Per- sonal Representatives appointed under infor- mal procedure. A copy of the Petition and Will, if any, can be obtained from the Petitioner. Run date 9/25/15 by Sal Giarratani the barber shop. He had so much hair that the barber charged $87 instead of the usual $I0. It was such a big job to do. How Yankees Get Their Numbers Retired If the NY Yankees keep retiring numbers, pretty soon the backs of jerseys will be listing social security numbers. Hall of Famers get their numbers retired. Everyone else gets a Bobblehead Day. Happy Birthdays Recently, Steve Curry turned 50, and Rick Wise turned 70. However, what caught my attention was the birthday of Bob Heffner, who recently turned 77. Except for baby boomers like myself, many have never even heard of Heffner before read- ing this piece. Back in the early dismal '60s, when the Red Sox didn't even have township status never-mind nationhood, they did have some good hurlers out in the bullpen. Bob Heffner was one of those guys who kept the Sox from looking even worse than they were. He was a spot starter from time-to- time, but mostly middle- inning long relief. He could get six to nine outs without too much trouble. He was of- ten the set-up guy for Dick Radatz, who came in to close out the game. Like Radatz, he was a big guy on the mound. It is hard to believe Heffner just turned 77 years old. Big Papi Gets Number 500 When I look at the long list of baseball players who have hit at least 500 career home runs, I still have my favorites and it is always because they hit more than anyone else. Forever, Hank Aaron, Babe Ruth and Willie Mays will be tops for me. I could care less about BaITy Bonds or A-Rod. I like Ken Griffey, Jr., and Frank Robinson. I like Reggie Jackson, Ted Will- iams, Ernie Banks, and Willie McCovey. Of course Mickey Mantle and Eddie Matthews, too. Outside of the 500 Club, I like Rick Monday, Jim Gentile and Rocky Colavito. And I will forever wonder what might have been for Tony Conigliaro. -- FOR YOU WHO APPRECIATE THE FINEST -- THE MUSIC FOR ALL OCCASIONS 781-648-5678 LEGAL NOTICE LEGAL NOTICE Commonwealth of Massachusetts The Trial Court Probate and Family Court Middlesex Division 208 Cambridge Street East Cambridge, MA 02141 (617) 768-5800 Docket No. MI15P4451EA Estate of BOOKER T. ABRAM, JR. Date of Death May 16, 2007 INFORMAL PROBATE PUBLICATION NOTICE To all persons interested in the above captioned estate, by Petition of Petitioner Maella Abram of Columbia, MS. Maella Abram of Columbia, MS ties been informally appointed as the Personal Repre- sentative of the estate to serve without surety on the bend. The estate is being administered under informal procedure by the Personal Represen- tative under the Massachusetts Uniform Pro- bate Code without supervision by the Court. Inventory and accounts are not required to be filed with the Court, but interested parties are entitled to notice regarding the administration from the Personal Representative and can pe~on the Court in any matter relating to the estate, including distribution of assets and expenses of administration. Interested parties are entitled to petition the Court to institute formal proceedings and to obtain orders terminating or restricting the powers of Per- sonal Representatives appointed under infor- mal procedure. A copy of the Petition and Will, if any, can be obtained from the Petitioner. Run date 9125/15 Commonwealth of Massachusetts The Trial Court Probate and Family Court Middlesex Division 208 Cambridge Street East Cambridge, MA 02141 (617) 768-5800 Docket No. MI15P4340EA Estate of HELEN H. BROWN Date of Death January 2, 2003 INFORMAL PROBATE PUBLICATION NOTICE To all persons interested in the above captioned estate, by Petition of Petitioner Anthony Brown of Jackson, MS. Anthony Brown of Jackson, MS has been informally appointed as the Personal Repre- sentative of the estate to serve without surety on the bond. The estate is being administered under informal procedure by the Personal Represen- tative under the Massachusetts Uniform Pro- bate Code without supervision by the Court. Inventory and accounts are not required to be filed with the Court, but interested parties are entitled to notice regarding the administration from the Personal Representative and can petition the Court in any matter relating to the estate, including distribution of assets and expenses of administration. Interested parties are entitled to petition the Court to institute formal proceedings and to obtain orders terminating or restricting the powers of Per- sonal Representatives appointed under infor- mal procedure. A copy of the Petition and Will, if any, can be obtained from the Petitioner. Run date 9/25/15 JO WWW. BOSTON POSTGAZ ETTE. COM